The case of Mato Žarić and others – acquittal for abuse of power charges
- Bosnia and Herzegovina
The case of Mato Žarić and others – acquittal for abuse of power charges
- Case Date(s)
- 12/2022
- Case Updated
- 02/2024
Case Summary
Phase
1st instance verdictOffence
- Abuse of functions
Institution
- Public enterprise: Elektroprijenos-Elektroprenos BiH
Involved people
- Politically exposed
- Yes
- — Abuse of functions
- Politically exposed
- Yes
- — Abuse of functions
- Politically exposed
- Yes
- — Abuse of functions
- Politically exposed
- Yes
- — Abuse of functions
- Politically exposed
- Yes
- — Abuse of functions
In December 2022, the prosecutor’s office of Bosnia and Herzegovina filed an indictment against Mato Žarić, the general director of the public company Elektroprijenos-Elektroprenos BiH, and four other company employees for allegedly causing damage to the company to the amount of KM455,000 (app. €230,000). The court of Bosnia and Herzegovina issued a first-instance verdict in February 2024, acquitting all of the accused of charges.
In December 2022, the prosecutor’s office of Bosnia and Herzegovina filed an indictment against Mato Žarić, the general director of the public company Elektroprijenos-Elektroprenos BiH, and four other company employees for abuse of position or authority for allegedly causing damage to the company to the amount of KM455,000 BAM (app. €230,000). The court of Bosnia and Herzegovina issued a first-instance verdict in February 2024, acquitting the accused of all charges.
The case involving five accused employees of the public enterprise Elektroprijenos-Elektroprenos BiH revolves around their actions between April 2015 and August 2018, resulting in allegedly securing financial benefit to the private company Elektroobnova at the expense of the public company Elektroprijenos-Elektroprenos BiH. According to the indictment, Elektroobnova was awarded a tender in 2015 to construct a transformer station in Šipovo. The contract stipulated the deadline to finish the works, as well as penalties for the contractor in case of delays.
Despite failures to finish the project in time, Elektroobnova suffered no financial penalties. According to the indictment, Mato Žarić, serving as the general director of Elektroprenos BiH, was accused of failing to collect a contractual penalty as per an agreement. Drago Malešević, as manager of the commercial affairs department, was alleged to have not calculated the contractual penalty, while Zoran Manojlović failed to properly document the claim and to forward it for further action and collection. Aleksandar Šukalo, in his capacity as a manager, was charged with not bringing to the attention of the executive director for finance the non-compliance with contractual obligations of the selected contractor, while Mila Bule, as the executive director for finance, was accused of neglecting to inform the general director about delays in contract implementation and the possibility of activating a bank guarantee.
During the trial, the prosecution submitted over 100 pieces of material evidence related to the tender’s documentation about the construction of transformer station in Šipovo, which pointed to delays in contract implementation.
On 21 February 2024, the court of Bosnia and Herzegovina delivered a first-instance verdict, acquitting the accused of the charges due to the lack of evidence. As this verdict is not legally-binding, the case is currently subject to appeal and further investigation to gather evidence for presentation by the prosecution.
Therefore, the final outcome of the case still remains uncertain. As the case in question involves a public enterprise, its development is of public interest and a matter of continuous discussion in terms of social and political affairs within the country.
Further details
- JURISDICTION/COURT
State/Court of BiH (Sud BiH)
- LAWS (ALLEGEDLY) BREACHED
Criminal Law of Bosnia and Herzegovina,
Article 220, para 3, abuse of position or authority
- FINAL SANCTION OR MEASURE
Acquittal
- PROSECUTOR
Ćazim Hasanspahić
- JUDGE
Mirsad Strika
Hasija Mašović
Goran Radević
SOCIAL HARM ON SDGs
16 Peace, justice and strong institutions
8 Decent work and economic growth
12 Responsible Consumption and Production
Acting as responsible persons in Elektroprijenos-Elektroprenos BiH, the accused allegedly took advantage of their official position, failed to perform their official duties, obtained material benefits for others and caused damage to the legal entity Elektroprijenos-Elektroprenos BiH to the amount of KM454,957 KM (€232,668.93 EUR) by failing to calculate and collect the contractual penalty and activate the bank guarantee.
Disclaimer
Every effort has been made to verify the accuracy of the information contained in this database. All information is believed to be correct as of 02/2024. Nevertheless, Transparency International cannot accept responsibility for the consequences of its use for other purposes or in other contexts.
Additional Material
-
Press release Link detektor.ba/2023/05/24/zaric-i-ostali-brojni-dokazi-o-prekoracenju-roka-za-zavrsetak-radova/Žarić and others: Numerous evidence of exceeding the deadline for completion of works
-
Press release Link n1info.ba/vijesti/sud-bih-izrice-presudu-u-predmetu-mato-zaric-i-ostali-elektroprijenos-bih-ostecen-za-skoro-pola-miliona-km/The Court of BiH pronounces a verdict in the case of 'Mato Žarić and others': Elektroprenos BiH damaged for almost half a million KM
-
Press release Link banjaluka.net/direktor-mato-zaric-i-cetiri-rukovodioca-optuzeni-da-su-ostetili-elektroprenos-bih-za-455-000-km/Director Mato Žarić and four executives accused of damaging Elektroprenos BiH for 455,000 KM
-
Press release Link radiosarajevo.ba/vijesti/bosna-i-hercegovina/sud-bih-osudeni-mato-zaric-mile-bule-alaksandar-sukalo-zoran-manojlovic-i-drago-malesevic/533922Elektroprenos case: Matan Žarić and others acquitted of charges of abuse of office
Contribute to this case
Do you have additional information, updates or relevant insights about this case? You can help by sharing new developments or legal updates on the case, providing verified sources that offer more context or evidence or highlighting public reactions or advocacy efforts related to the case.
Do you know of a corruption case that has been reported in the media or by civil society, or is already in the judicial process but is not receiving enough attention? Help us put a spotlight on key corruption cases in your country, and we will review your suggestion and consider adding it to the corruption database.
Please only suggest cases that have already been reported by the media or civil society or cases that are in some stage of the law enforcement or judicial process. If you would like to report a new corruption case, please reach out to our Advocacy and Legal Advice Centres in your country or email us.